FAR and DFARS › FAR Part 16: Types of Contracts › Subpart 16.4
FAR 16.402-3 Delivery incentives.
The codified text (eCFR, as of 2026-10-02). Under the Revolutionary FAR Overhaul ↗, agencies follow class deviations with new text for many parts while the formal rules go through the Federal Register: check the solicitation and your contract's clauses, which rule.
In plain English
This section says delivery incentives should be considered when faster delivery than the required schedule is a significant Government objective, and that the Government's primary objectives should be identified. It also requires delivery incentive arrangements to specify how the reward-penalty structure applies to Government-caused delays or other delays beyond the contractor's control and without fault or negligence.
Applies to: Contracting officers and contractors on contracts using delivery incentives
What it requires
- Consider delivery incentives when improvement from the required delivery schedule is a significant Government objective
- Determine the Government's primary objectives in the contract
- Specify in delivery incentive arrangements the application of the reward-penalty structure for Government-caused delays or other delays beyond the contractor's or subcontractor's control and without fault or negligence
Key terms: delivery incentives · required delivery schedule · reward-penalty structure · Government-caused delays · subcontractor
Written by AI from this section's text. A guide, not legal advice: the text below rules.
The text
(a) Delivery incentives should be considered when improvement from a required delivery schedule is a significant Government objective. It is important to determine the Government's primary objectives in a given contract (e.g., earliest possible delivery or earliest quantity production).
(b) Incentive arrangements on delivery should specify the application of the reward-penalty structure in the event of Government-caused delays or other delays beyond the control, and without the fault or negligence, of the contractor or subcontractor.
← 16.402-2 Performance incentives. · 16.402-4 Structuring multiple-incentive contracts. →
Rule changes for FAR Part 16
- Federal Acquisition Regulation: Revolutionary Federal Acquisition Regulation Overhaul Parts 16, 17, and 35 ↗ · proposed 2026-09-18 · comments due 2026-10-19
- Federal Acquisition Regulation: Inflation Adjustment of Acquisition-Related Thresholds ↗ · final rule 2025-08-27 · effective 2025-10-01
- Federal Acquisition Regulation: Protests of Orders Under Certain Multiple-Award Contracts ↗ · proposed 2025-06-12
- Federal Acquisition Regulation: Small Business Participation on Certain Multiple-Award Contracts ↗ · proposed 2025-06-12
- Federal Acquisition Regulation: Protests of Orders Under Certain Multiple-Award Contracts ↗ · proposed 2025-01-15 · comments due 2025-03-17
- Federal Acquisition Regulation: Small Business Participation on Certain Multiple-Award Contracts ↗ · proposed 2025-01-15 · comments due 2025-03-17
- Federal Acquisition Regulation: Preventing Organizational Conflicts of Interest in Federal Acquisition ↗ · proposed 2025-01-15 · comments due 2025-03-17
- Federal Acquisition Regulation: Rerepresentation of Size and Socioeconomic Status ↗ · final rule 2025-01-03 · effective 2025-01-17
Source: eCFR, 48 CFR chapters 1 and 2 (GPO GovInfo bulk data) ↗. Plain words for the terms: glossary.