48 CFR · Federal Acquisition Regulation and Defense supplement
FAR and DFARS navigator
The codified text (eCFR, as of 2026-10-02). Under the Revolutionary FAR Overhaul ↗, agencies follow class deviations with new text for many parts while the formal rules go through the Federal Register: check the solicitation and your contract's clauses, which rule.
Ask the FAR
Try: · · ·
37 sections with “extended price”
- FAR 52.249-2 Termination for Convenience of the Government (Fixed-Price).…inventory schedules no later than 120 days from the effective date of termination, unless extended in writing by the Contracting Officer upon written request of the Contractor within this 120-day period. (d) After expiration of the plant c…
- FAR 52.222-32 Construction Wage Rate Requirements—Price Adjustment (Actual Method).…n 30 days after receiving a revised wage determination unless this notification period is extended in writing by the Contracting Officer. The Contractor shall notify the Contracting Officer promptly of any decrease under this clause, but no…
- FAR 52.249-6 Termination (Cost-Reimbursement).…defaults in performing this contract and fails to cure the default within 10 days (unless extended by the Contracting Officer) after receiving a notice specifying the default. Default includes failure to make progress in the work so as to e…
- FAR 52.249-10 Default (Fixed-Price Construction).…uppliers; and (2) The Contractor, within 10 days from the beginning of any delay (unless extended by the Contracting Officer), notifies the Contracting Officer in writing of the causes of delay. The Contracting Officer shall ascertain the …
- FAR 8.405-4 Price reductions.… Schedule contractors are not required to pass on to all schedule users a price reduction extended only to an individual ordering activity for a specific order or BPA.
- FAR 52.214-12 Preparation of Bids.…uding, unless otherwise specified, packaging, packing, and preservation and (2) enter the extended price for the quantity of each item offered in the Amount column of the Schedule. In case of discrepancy between a unit price and an extended…
- FAR 52.222-43 Fair Labor Standards Act and Service Contract Labor Standards—Price Adjustment (Multiple Year and Option Contracts).…ithin 30 days after receiving a new wage determination unless this notification period is extended in writing by the Contracting Officer. The Contractor shall promptly notify the Contracting Officer of any decrease under this clause, but no…
- FAR 52.222-44 Fair Labor Standards Act and Service Contract Labor Standards—Price Adjustment.… clause within 30 days after the effective date of the wage change, unless this period is extended by the Contracting Officer in writing. The Contractor shall promptly notify the Contracting Officer of any decrease under this clause, but no…
- FAR 32.905 Payment documentation and process.…mber and line item number). (iv) Description, quantity, unit of measure, unit price, and extended price of supplies delivered or services performed. (v) Shipping and payment terms (e.g., shipment number and date of shipment, discount for …
- FAR 52.212-4 Contract Terms and Conditions—Commercial Products and Commercial Services.…pplicable, the order number; (iv) Description, quantity, unit of measure, unit price and extended price of the items delivered; (v) Shipping number and date of shipment, including the bill of lading number and weight of shipment if shippe…
- FAR 52.232-25 Prompt payment.…mber and line item number). (iv) Description, quantity, unit of measure, unit price, and extended price of supplies delivered or services performed. (v) Shipping and payment terms (e.g., shipment number and date of shipment, discount for …
- FAR 52.249-3 Termination for Convenience of the Government (Dismantling, Demolition, or Removal of Improvements).…inventory schedules no later than 120 days from the effective date of termination, unless extended in writing by the Contracting Officer upon written request of the Contractor within this 120-day period. (d) After expiration of the plant c…
- DFARS 252.232-7011 Payments in Support of Emergencies and Contingency Operations.…contract line item number). (iv) Description, quantity, unit of measure, unit price, and extended price of supplies delivered or services performed. (v) Shipping and payment terms (e.g., shipment number and date of shipment, discount for …
- FAR 48.201 Clauses for supply or service contracts.…he VECP is accepted.” for “the number of future contract units in the sharing base.” (h) Extended production period solicitations and contracts. In solicitations and contracts for items requiring an extended period for production (e.g., sh…
- FAR 52.212-5 Contract Terms and Conditions Required To Implement Statutes or Executive Orders—Commercial Products and Commercial Services.… (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (2) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kaspers…
- FAR 52.249-5 Termination for Convenience of the Government (Educational and Other Nonprofit Institutions).…inventory schedules no later than 120 days from the effective date of termination, unless extended in writing by the Contracting Officer upon written request of the Contractor within this 120-day period. (d) After termination, the Contract…
- DFARS 204.7104-1 Criteria for establishing.…manufacturer's part number, scope of work, description of services). (3) Unit prices and extended amounts. (i) The unit price and total amount for all subline items may be entered at the contract line item number level if the unit price f…
- FAR 14.503-1 Step one.…porate such additional information as part of their proposals submitted. Such time may be extended in the discretion of the contracting officer. If the additional information incorporated as part of a proposal within the final time fixed by…
- FAR 16.203-2 Application.…us doubt concerning the stability of market or labor conditions that will exist during an extended period of contract performance, and (ii) contingencies that would otherwise be included in the contract price can be identified and covered s…
- FAR 16.203-4 Contract clauses.…cost indexes of labor or materials may be appropriate when— (i) The contract involves an extended period of performance with significant costs to be incurred beyond 1 year after performance begins; (ii) The contract amount subject to adju…
- FAR 22.404-5 Expiration of project wage determinations.…t is granted, the contracting officer shall award the contract and modify it to apply the extended expiration date to the already incorporated project wage determination. (See 43.103(b)(1).) If the request is denied, the Administrator will …
- FAR 28.101-2 Solicitation provision or contract clause.…ons for negotiated contracts; or (4) For use in service contracts containing options for extended performance. (b) The contracting officer shall determine the amount of the bid guarantee for insertion in the provision at 52.228-1 (see 28.…
- FAR 31.205-6 Compensation for personal services.… current year, but not funded, paid or otherwise liquidated by the tax return due date as extended are not allowable in any subsequent year. (4) Increased PRB costs caused by delay in funding beyond 30 days after each quarter of the year t…
- FAR 32.904 Determining payment due dates.…ct file the justification for extending the constructive acceptance period beyond 7 days. Extended acceptance periods must not be a routine agency practice and must be used only when necessary to permit proper Government inspection and test…
- FAR 42.302 Contract administration functions.… Designator of C (see 42.1105). Notification that the contract delivery schedule is being extended shall be provided to the contracting office. Subsequent extensions on any individual contract shall be authorized only upon concurrence of th…
- FAR 52.211-10 Commencement, Prosecution, and Completion of Work.…he notice to proceed by __ [Contracting Officer insert date]. The completion date will be extended by the number of calendar days after the above date that the Contractor receives the notice to proceed, except to the extent that the delay i…
- FAR 52.212-1 Instructions to Offerors—Commercial Products and Commercial Services.…ension of the closing date, the time specified for receipt of offers will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume. (5) Offers may be w…
- FAR 52.212-3 Offeror Representations and Certifications—Commercial Products and Commercial Services.… (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions), Government agencies are not permitted to use appropriated (or otherwise made available) funds for contracts with …
- FAR 52.213-4 Terms and Conditions—Simplified Acquisitions (Other Than Commercial Products and Commercial Services).… (Pub. L. 113-235) and its successor provisions in subsequent appropriations acts (and as extended in continuing resolutions)). (ii) 52.204-23, Prohibition on Contracting for Hardware, Software, and Services Developed or Provided by Kasper…
- FAR 52.215-1 Instructions to Offerors—Competitive Acquisition.…ent of the solicitation, the time specified for receipt of proposals will be deemed to be extended to the same time of day specified in the solicitation on the first work day on which normal Government processes resume. (v) Proposals may b…
- FAR 52.219-28 Postaward Small Business Program Rerepresentation.…e contracts that exceed five years in duration because the period of performance has been extended for a cumulative period not to exceed six months under the clause at 52.217-8, Option to Extend Services, or other appropriate authority. Sm…
- DFARS 217.172 Multiyear contracts for supplies.…enter into or extend a multiyear contract that exceeds $900 million (when entered into or extended) until the Secretary of Defense identifies the contract and any extension in a report submitted to the congressional defense committees (10 U…
- DFARS 217.7404-3 Definitization schedule.…that is 180 days after the contractor submits a qualifying proposal. This date may not be extended beyond an additional 90 days without a written determination by the head of the contracting activity without power of redelegation, the comma…
- DFARS 243.204-70-3 Definitization schedule.…r of— (1) The date that is 180 days after issuance of the change order (this date may be extended but may not exceed the date that is 180 days after the contractor submits a qualifying proposal); or (2) The date on which the amount of fun…
- DFARS 246.704 Authority for use of warranties.…mercial services (see FAR 46.709); (ii) Technical data, unless the warranty provides for extended liability (see 246.708); (iii) Supplies and services in fixed-price type contracts containing quality assurance provisions that reference hi…
- DFARS 246.708 Warranties of data.…to obtain warranties of technical data. Consider the following in deciding whether to use extended liability provisions— (1) The likelihood that correction or replacement of the nonconforming data, or a price adjustment, will not give adeq…
- DFARS 252.227-7018 Rights in Other Than Commercial Technical Data and Computer Software—Small Business Innovation Research Program and Small Business Technology Transfer Program.… SBIR/STTR data developed or generated under this contract. This protection period is not extended by any subsequent SBIR/STTR contracts under which any portion of that SBIR/STTR data is used or delivered. The SBIR/STTR data protection peri…
FAR (chapter 1)
- Part 1 Federal Acquisition Regulations System 58 sections
- Part 2 Definitions of Words and Terms 3 sections
- Part 3 Improper Business Practices and Personal Conflicts of Interest 98 sections
- Part 4 Administrative and Information Matters 116 sections
- Part 5 Publicizing Contract Actions 34 sections
- Part 6 Competition Requirements 34 sections
- Part 7 Acquisition Planning 34 sections
- Part 8 Required Sources of Supplies and Services 67 sections
- Part 9 Contractor Qualifications 106 sections
- Part 10 Market Research 4 sections
- Part 11 Describing Agency Needs 33 sections
- Part 12 Acquisition of Commercial Products and Commercial Services 38 sections
- Part 13 Simplified Acquisition Procedures 49 sections
- Part 14 Sealed Bidding 82 sections
- Part 15 Contracting by Negotiation 81 sections
- Part 16 Types of Contracts 74 sections
- Part 17 Special Contracting Methods 50 sections
- Part 18 Emergency Acquisitions 34 sections
- Part 19 Small Business Programs 126 sections
- Part 22 Application of Labor Laws to Government Acquisitions 205 sections
- Part 23 Environment, Sustainable Acquisition, and Material Safety 38 sections
- Part 24 Protection of Privacy and Freedom of Information 10 sections
- Part 25 Foreign Acquisition 81 sections
- Part 26 Other Socioeconomic Programs 36 sections
- Part 27 Patents, Data, and Copyrights 59 sections
- Part 28 Bonds and Insurance 61 sections
- Part 29 Taxes 23 sections
- Part 30 Cost Accounting Standards Administration 30 sections
- Part 31 Contract Cost Principles and Procedures 87 sections
- Part 32 Contract Financing 175 sections
- Part 33 Protests, Disputes, and Appeals 23 sections
- Part 34 Major System Acquisition 20 sections
- Part 35 Research and Development Contracting 25 sections
- Part 36 Construction and Architect-engineer Contracts 81 sections
- Part 37 Service Contracting 46 sections
- Part 38 Federal Supply Schedule Contracting 3 sections
- Part 39 Acquisition of Information Technology 14 sections
- Part 40 Information Security and Supply Chain Security 12 sections
- Part 41 Acquisition of Utility Services 17 sections
- Part 42 Contract Administration and Audit Services 84 sections
- Part 43 Contract Modifications 14 sections
- Part 44 Subcontracting Policies and Procedures 24 sections
- Part 45 Government Property 33 sections
- Part 46 Quality Assurance 60 sections
- Part 47 Transportation 106 sections
- Part 48 Value Engineering 13 sections
- Part 49 Termination of Contracts 108 sections
- Part 50 Extraordinary Contractual Actions and the Safety Act 34 sections
- Part 51 Use of Government Sources by Contractors 15 sections
- Part 52 Solicitation Provisions and Contract Clauses 680 sections
- Part 53 Forms 61 sections
DFARS (chapter 2, Defense)
- Part 201 Federal Acquisition Regulations System 24 sections
- Part 202 Definitions of Words and Terms 1 sections
- Part 203 Improper Business Practices and Personal Conflicts of Interest 28 sections
- Part 204 Administrative and Information Matters 76 sections
- Part 205 Publicizing Contract Actions 11 sections
- Part 206 Competition Requirements 20 sections
- Part 207 Acquisition Planning 22 sections
- Part 208 Required Sources of Supplies and Services 31 sections
- Part 209 Contractor Qualifications 55 sections
- Part 210 Market Research 2 sections
- Part 211 Describing Agency Needs 22 sections
- Part 212 Acquisition of Commercial Products and Commercial Services 24 sections
- Part 213 Simplified Acquisition Procedures 23 sections
- Part 214 Sealed Bidding 14 sections
- Part 215 Contracting by Negotiation 66 sections
- Part 216 Types of Contracts 36 sections
- Part 217 Special Contracting Methods 64 sections
- Part 218 Emergency Acquisitions 7 sections
- Part 219 Small Business Programs 47 sections
- Part 222 Application of Labor Laws to Government Acquisitions 56 sections
- Part 223 Environment, Sustainable Acquisition, and Material Safety 34 sections
- Part 224 Protection of Privacy and Freedom of Information 2 sections
- Part 225 Foreign Acquisition 251 sections
- Part 226 Other Socioeconomic Programs 14 sections
- Part 227 Patents, Data, and Copyrights 99 sections
- Part 228 Bonds and Insurance 17 sections
- Part 229 Taxes 9 sections
- Part 230 Cost Accounting Standards Administration 2 sections
- Part 231 Contract Cost Principles and Procedures 13 sections
- Part 232 Contract Financing 74 sections
- Part 233 Protests, Disputes, and Appeals 8 sections
- Part 234 Major System Acquisition 13 sections
- Part 235 Research and Development Contracting 16 sections
- Part 236 Construction and Architect-engineer Contracts 25 sections
- Part 237 Service Contracting 67 sections
- Part 239 Acquisition of Information Technology 38 sections
- Part 241 Acquisition of Utility Services 8 sections
- Part 242 Contract Administration and Audit Services 40 sections
- Part 243 Contract Modifications 18 sections
- Part 244 Subcontracting Policies and Procedures 13 sections
- Part 245 Government Property 23 sections
- Part 246 Quality Assurance 39 sections
- Part 247 Transportation 27 sections
- Part 249 Termination of Contracts 14 sections
- Part 250 Extraordinary Contractual Actions and the Safety Act 16 sections
- Part 251 Use of Government Sources by Contractors 5 sections
- Part 252 Solicitation Provisions and Contract Clauses 405 sections
- Part 253 Forms 10 sections
- Part 270 Defense Contracting Programs 7 sections
Source: eCFR, 48 CFR chapters 1 and 2 (GPO GovInfo bulk data) ↗. Rule changes in progress: FAR, DFARS. Terms: glossary.