SpendQueryBeta

48 CFR · Federal Acquisition Regulation and Defense supplement

FAR and DFARS navigator

The codified text (eCFR, as of 2026-10-02). Under the Revolutionary FAR Overhaul ↗, agencies follow class deviations with new text for many parts while the formal rules go through the Federal Register: check the solicitation and your contract's clauses, which rule.

Ask the FAR

Try: · · ·

Clear

77 sections with “liquidated”: the first 40

  • FAR 22.302 Liquidated damages and overtime pay.
    …sible contractor or subcontractor must pay the affected employee any unpaid wages and pay liquidated damages to the Government. The contracting officer must assess liquidated damages at the rate specified at 29 CFR 5.5(b)(2) per affected em…
  • FAR 52.211-11 Liquidated Damages—Supplies, Services, or Research and Development.
    As prescribed in 11.503(a), insert the following clause in solicitations and contracts: Liquidated Damages—Supplies, Services, or Research and Development (SEP 2000) (a) If the Contractor fails to deliver the supplies or perform the servi…
  • DFARS 222.302 Liquidated damages and overtime pay.
    …e contractor written notification of the withholding and a statement of the basis for the liquidated damages assessment. The written notification shall also inform the contractor of its 60 days right to appeal the assessment, through the co…
  • FAR 52.211-12 Liquidated Damages—Construction.
    As prescribed in 11.503(b), insert the following clause in solicitations and contracts: Liquidated Damages—Construction (SEP 2000) (a) If the Contractor fails to complete the work within the time specified in the contract, the Contractor …
  • FAR 52.219-16 Liquidated Damages—Subcontracting Plan.
    As prescribed in 19.708(b)(2), insert the following clause: Liquidated Damages—Subcontracting Plan (SEP 2021) (a) Failure to make a good faith effort to comply with the subcontracting plan, as used in this clause, means a willful or inten…
  • FAR 32.503-12 Maximum unliquidated amount.
    (a) The contracting officer shall ensure that any excess of the unliquidated progress payments over the contractual limitation in paragraph (a) of the Progress Payments clause in the contract is promptly corrected through one or more of the…
  • FAR 36.206 Liquidated damages.
    The contracting officer must evaluate the need for liquidated damages in a construction contract in accordance with 11.502 and agency regulations.
  • DFARS 236.206 Liquidated damages.
    See 211.503 for instructions on use of liquidated damages.
  • FAR 11.501 Policy.
    … the potential impact on pricing, competition, and contract administration before using a liquidated damages clause. Use liquidated damages clauses only when— (1) The time of delivery or timely performance is so important that the Governme…
  • FAR 11.502 Procedures.
    (a) Include the applicable liquidated damages clause and liquidated damages rates in solicitations when the contract will contain liquidated damages provisions. (b) Construction contracts with liquidated damages provisions must describe th…
  • FAR 11.503 Contract clauses.
    (a) Use the clause at 52.211-11, Liquidated Damages—Supplies, Services, or Research and Development, in fixed-price solicitations and contracts for supplies, services, or research and development when the contracting officer determines that…
  • FAR 19.705-7 Compliance with the subcontracting plan.
    …tracting plan, these objectives are not achieved, and 15 U.S.C. 637(d)(4)(F) directs that liquidated damages shall be paid by the contractor. (b) Determination of good faith effort. (1) In determining whether a contractor failed to make a …
  • FAR 22.406-8 Investigations.
    … material obtained from Labor Department files, other than computations of back wages and liquidated damages and summaries of back wages due, to anyone other than Government contract administrators. (b) Investigation report. The contractin…
  • FAR 22.406-9 Withholding from or suspension of contract payments.
    …ments due the contractor an amount equal to the estimated wage underpayment and estimated liquidated damages due the United States under the Contract Work Hours and Safety Standards statute. (See 22.302.) (1) If the contracting officer bel…
  • FAR 52.222-4 Contract Work Hours and Safety Standards—Overtime Compensation.
    …te of pay for each hour worked over 40 hours. (b) Violation; liability for unpaid wages; liquidated damages. The responsible Contractor and subcontractor are liable for unpaid wages if they violate the terms in paragraph (a) of this clause…
  • FAR 52.232-12 Advance Payments.
    …ny advance payments to subcontractors. (b) Special account. Until (1) the Contractor has liquidated all advance payments made under the contract and related interest charges and (2) the administering office has approved in writing the rele…
  • FAR 52.232-16 Progress Payments.
    …nd-material subcontracts to which the Contractor has acquired title. (5) The amount of unliquidated progress payments may exceed neither (i) the progress payments made against incomplete work (including allowable unliquidated progress paym…
  • FAR 52.232-30 Installment Payments for Commercial Products and Commercial Services.
    …uest for payment. (e) Liquidation of installment payments. Installment payments shall be liquidated by deducting from the delivery payment of each item the total unliquidated amount of installment payments made for that separately priced u…
  • DFARS 219.702-70 Statutory requirements for the Test Program for Negotiation of Comprehensive Small Business Subcontracting Plans.
    …ractor written notice specifying the failure, advising of the potential for assessment of liquidated damages, permitting the contractor to demonstrate what good faith efforts have been made, and providing a period of 15 working days (or lon…
  • DFARS 222.406-9 Withholding from or suspension of contract payments.
    … liability for Construction Wage Rate Requirements or CWHSS statute wage underpayments or liquidated damages. (c) Disposition of contract payments withheld or suspended—(3) Limitation on forwarding or returning funds. When disposition of w…
  • DFARS 252.219-7004 Small Business Subcontracting Plan (Test Program).
    …n approved plan required by this clause, shall be a material breach of the contract. (f) Liquidated damages. The Contracting Officer designated to manage the comprehensive subcontracting plan will exercise the functions of the Contracting …
  • FAR 32.202-4 Security for Government financing.
    …y find acceptable. (3) The value of the security must be at least equal to the maximum unliquidated amount of contract financing payments to be made to the contractor. The value of security may be adjusted periodically during contract perf…
  • FAR 52.232-32 Performance-Based Payments.
    … Performance-based finance amounts paid prior to payment for delivery of an item shall be liquidated by deducting a percentage or a designated dollar amount from the delivery payment. If the performance-based finance payments are on a deliv…
  • DFARS 252.217-7009 Default.
    …n lieu of actual damage, the Contractor shall pay to the Government as fixed, agreed, and liquidated damages for each calendar day of delay the amount, if any, set forth in the job order (prorated to the nearest hour for fractional days). …
  • FAR 11.500 Scope.
    (a) This subpart prescribes policies and procedures for using liquidated damages clauses in solicitations and contracts for supplies, services, research and development, and construction. (b) This subpart does not apply to liquidated damag…
  • FAR 19.705-6 Postaward responsibilities of the contracting officer.
    …eparing and submitting the bid or proposal, if applicable. (h) Initiate action to assess liquidated damages in accordance with 19.705-7 upon a recommendation by the administrative contracting officer, if one is assigned, or receipt of othe…
  • FAR 22.2109 Enforcement of Executive Order 13706 paid sick leave requirements.
    …result of the violation; or (C) Appropriate equitable or other relief. (iii) Payment of liquidated damages in an amount equaling any monetary relief may also be directed unless such amount is reduced by the Administrator of the Wage and H…
  • FAR 32.206 Solicitation provisions and contract clauses.
    …nancing payments; that is, financing payments computed on a whole contract basis shall be liquidated on a whole contract basis; and a payment computed on a line item basis shall be liquidated against that line item. If liquidation is on a w…
  • FAR 32.407 Interest.
    …ided in paragraph (d) below, the contracting officer shall charge interest on the daily unliquidated balance of all advance payments at the higher of— (1) The published prime rate of the financial institution (depository) in which the spec…
  • FAR 32.503-6 Suspension or reduction of payments.
    …he contracting officer shall suspend progress payments and all other payments until the unliquidated balance of progress payments is eliminated. (d) Excessive inventory. If the inventory allocated to the contract exceeds reasonable require…
  • FAR 32.503-11 Adjustments for price reduction.
    …vered items over amounts due as recomputed at the reduced prices; and (2) Increase the unliquidated progress payments amount for overdeductions made from the contractor's billings for items delivered. (b) The contracting officer shall als…
  • FAR 49.206-2 Bases for settlement proposals.
    …stment for loss (49.203(b)) must be made to complete the gross settlement proposal. All unliquidated advance and progress payments and all disposal and other credits known when the proposal is submitted must then be deducted. (3) This inve…
  • FAR 49.603-1 Fixed-price contracts—complete termination.
    …less amount shown in subdivision (6)(i) above], (A) the amount of $____________ for all unliquidated partial or progress payments previously made to the Contractor or its assignee and all unliquidated advance payments (with any interest) an…
  • FAR 49.603-2 Fixed-price contracts—partial termination.
    …__________ [insert gross amount of settlement], (A) the amount of $____________ for all unliquidated partial or progress payments previously made to the Contractor or its assignee and all unliquidated advance payments (with any interest) ap…
  • FAR 49.603-3 Cost-reimbursement contracts—complete termination, if settlement includes cost.
    …nt less amount shown in subdivision (6)(i) above] (A) the amount of $__________ for all unliquidated partial or progress payments previously made to the Contractor or its assignee and all unliquidated advance payments (with any interest), (…
  • FAR 52.232-29 Terms for Financing of Purchases of Commercial Products and Commercial Services.
    …nated for cause, the Contractor shall, on demand, repay to the Government the amount of unliquidated contract financing payments. The Government shall be liable for no payment except as provided by the Termination for Cause paragraph of the…
  • DFARS 211.500 Scope.
    This subpart and FAR subpart 11.5 do not apply to liquidated damages for comprehensive subcontracting plans under the Test Program for Negotiation of Comprehensive Small Business Subcontracting Plans. See 219.702-70 for coverage of liquidat…
  • DFARS 219.708 Contract clauses.
    …lan (DoD Contracts), FAR 52.219-9, Small Business Subcontracting Plan, and FAR 52.219-16, Liquidated Damages—Subcontracting Plan. (2) In contracts with contractors that have comprehensive subcontracting plans approved under the Test Progra…
  • DFARS 222.406-8 Investigations.
    …tion. (4)(A) Notify the contractor by certified mail of any finding that it is liable for liquidated damages under the Contract Work Hours and Safety Standards (CWHSS) statute. The notification shall inform the contractor that— (1) It has …
  • FAR 11.401 General.
    …ormance. (c) If timely delivery or performance is unusually important to the Government, liquidated damages clauses may be used (see subpart 11.5).

FAR (chapter 1)

DFARS (chapter 2, Defense)

Source: eCFR, 48 CFR chapters 1 and 2 (GPO GovInfo bulk data) ↗. Rule changes in progress: FAR, DFARS. Terms: glossary.