SpendQueryBeta

48 CFR · Federal Acquisition Regulation and Defense supplement

FAR and DFARS navigator

The codified text (eCFR, as of 2026-10-02). Under the Revolutionary FAR Overhaul ↗, agencies follow class deviations with new text for many parts while the formal rules go through the Federal Register: check the solicitation and your contract's clauses, which rule.

Ask the FAR

Try: · · ·

Clear

211 sections with “completion”: the first 40

  • FAR 52.211-10 Commencement, Prosecution, and Completion of Work.
    …ers under indefinite-delivery contracts for construction. Commencement, Prosecution, and Completion of Work (APR 1984) The Contractor shall be required to (a) commence work under this contract within __ [Contracting Officer insert number]…
  • FAR 49.405 Completion by another contractor.
    If the surety does not arrange for completion of the contract, the contracting officer normally will arrange for completion of the work by awarding a new contract based on the same plans and specifications. The new contract may be the resul…
  • FAR 52.236-11 Use and Possession Prior to Completion.
    As prescribed in 36.511, insert the following clause: Use and Possession Prior to Completion (APR 1984) (a) The Government shall have the right to take possession of or use any completed or partially completed part of the work. Before tak…
  • FAR 36.511 Use and possession prior to completion.
    The contracting officer shall insert the clause at 52.236-11, Use and Possession Prior to Completion, in solicitations and contracts when a fixed-price construction contract is contemplated and the contract award amount is expected to excee…
  • DFARS 253.213-70 Completion of DD Form 1155, Order for Supplies or Services.
    Follow the procedures at PGI 253.213-70 for completion of DD Form 1155.
  • FAR 13.303-7 Completion of BPAs.
    An individual BPA is considered complete when the purchases under it equal its total dollar limitation, if any, or when its stated time period expires.
  • FAR 11.402 Factors to consider in establishing schedules.
    …ct; e.g., furnishing Government property. (b) Construction. When scheduling the time for completion of a construction contract, the contracting officer shall consider applicable factors such as the— (1) Nature and complexity of the projec…
  • FAR 49.305-2 Construction contracts.
    (a) The percentage of completion basis refers to the contractor's total effort and not solely to the actual construction work. Generally, the effort of a contractor under a cost-reimbursement construction or professional services contract c…
  • FAR 50.103-4 Facts and evidence.
    …nt of the contractor's remaining obligations, and the contractor's expectations regarding completion. (3) A statement of payments received, due, and yet to be received or to become due, including advance and progress payments; amounts with…
  • FAR 52.216-7 Allowable Cost and Payment.
    …cost rates for all years of a physically complete contract, the Contractor shall submit a completion invoice or voucher to reflect the settled amounts and rates. The completion invoice or voucher shall include settled subcontract amounts an…
  • FAR 52.232-12 Advance Payments.
    … the contract price, the Government shall withhold further payments to the Contractor. On completion or termination of the contract, the Government shall deduct from the amount due to the Contractor all unliquidated advance payments and all…
  • FAR 52.241-9 Connection Charge.
    …bill. (2) In the event the Contractor, before any termination of this contract but after completion of the facilities provided for in this clause, serves any customer other than the Government (regardless of whether the Government is being…
  • FAR 52.245-1 Government Property.
    …lans thereunder or of the termination of the contract (or subcontract thereunder), before completion of the work, for the convenience or at the option of the Government; and (3) Government-furnished property that exceeds the amounts needed…
  • FAR 16.306 Cost-plus-fixed-fee contracts.
    …contracting officer complies with all limitations in 15.404-4(c)(4)(i) and 16.301-3. (d) Completion and term forms. A cost-plus-fixed-fee contract may take one of two basic forms—completion or term. (1) The completion form describes the s…
  • FAR 19.704 Subcontracting plan requirements.
    … and September 30. A report is also required for each contract within 30 days of contract completion. Reports are due 30 days after the close of each reporting period, unless otherwise directed by the contracting officer. Reports are requir…
  • FAR 32.1004 Procedures.
    … criterion. (2) Events or criteria may be either severable or cumulative. The successful completion of a severable event or criterion is independent of the accomplishment of any other event or criterion. Conversely, the successful accompli…
  • FAR 52.211-13 Time Extensions.
    …ract changes will depend upon the extent, if any, by which the changes cause delay in the completion of the various elements of construction. The change order granting the time extension may provide that the contract completion date will be…
  • FAR 52.212-4 Contract Terms and Conditions—Commercial Products and Commercial Services.
    …ct. (viii) Upon receipt and approval of the invoice designated by the Contractor as the “completion invoice” and supporting documentation, and upon compliance by the Contractor with all terms of this contract, any outstanding balances will…
  • FAR 52.219-9 Small Business Subcontracting Plan.
    …itten explanation must be submitted to the Contracting Officer within 30 days of contract completion. (14) Assurances that the Contractor will not prohibit a subcontractor from discussing with the Contracting Officer any material matter pe…
  • FAR 52.232-7 Payments under Time-and-Materials and Labor-Hour Contracts.
    …erpayments. Upon receipt and approval of the voucher designated by the Contractor as the “completion voucher” and supporting documentation, and upon compliance by the Contractor with all terms of this contract (including, without limitation…
  • DFARS 252.236-7004 Payment for mobilization and demobilization.
    …e contract lump sum price for this item. (1) ________ percent of the lump sum price upon completion of the contractor's mobilization at the work site. (2) The remaining ________ percent upon completion of demobilization. (b) The Contract…
  • FAR 4.804-1 Closeout by the office administering the contract.
    …in 6 months after the date on which the contracting officer receives evidence of physical completion. (3) Files for contracts requiring settlement of indirect cost rates should be closed within 36 months of the month in which the contracti…
  • FAR 14.404-1 Cancellation of invitations after opening.
    …ties, if any) in order to avoid the need for resoliciting. (e) Under some circumstances, completion of the acquisition after cancellation of the invitation for bids may be appropriate. (1) If the invitation for bids has been cancelled for…
  • FAR 49.404 Surety-takeover agreements.
    …sulting from the contractor's default, the surety has certain rights and interests in the completion of the contract work and application of any undisbursed funds. Therefore, the contracting officer must consider carefully the surety's prop…
  • FAR 52.222-41 Service Contract Labor Standards.
    …the Service Contract Labor Standards statute shall make and maintain for 3 years from the completion of the work, and make them available for inspection and transcription by authorized representatives of the Wage and Hour Division, a record…
  • FAR 52.237-4 Payment by Government to Contractor.
    …ents the Contracting Officer shall retain 10 percent of the estimated payment until final completion and acceptance of the contract work. However, if the Contracting Officer finds that satisfactory progress was achieved during any period fo…
  • FAR 52.249-6 Termination (Cost-Reimbursement).
    …vernment, the settlement shall include a percentage of the fee equal to the percentage of completion of work contemplated under the contract, but excluding subcontract effort included in subcontractors' termination proposals, less previous …
  • FAR 52.249-10 Default (Fixed-Price Construction).
    …ails to prosecute the work or any separable part, with the diligence that will insure its completion within the time specified in this contract including any extension, or fails to complete the work within this time, the Government may, by …
  • DFARS 236.270 Expediting construction contracts.
    (a) 10 U.S.C. 2858 requires agency head approval to expedite the completion date of a contract funded by a Military Construction Appropriations Act, if additional costs are involved. This approval authority may not be redelegated. The appro…
  • DFARS 252.217-7007 Payments.
    …nts (DEC 1991) (a) Progress payments, as used in this clause, means payments made before completion of work in progress under a job order. (b) Upon submission by the Contractor of invoices in the form and number of copies directed by the …
  • DFARS 252.246-7001 Warranty of data.
    …her requirements of this contract. The warranty period shall extend for three years after completion of the delivery of the line item of data (as identified in DD Form 1423, Contract Data Requirements List) of which the data forms a part; o…
  • FAR 2.101 Definitions.
    …the contracting officer, that its disclosure would jeopardize the integrity or successful completion of the Federal agency procurement to which the information relates. Special competency means a special or unique capability, including qua…
  • FAR 4.803 Contents of contract files.
    … copyright reports (including invention disclosures) or reference thereto. (37) Contract completion documents. (38) Documentation regarding termination actions for which the contracting office is responsible. (39) Cross-references to per…
  • FAR 4.804-5 Procedures for closing out contract files.
    … manual) administrative closeout of the contract after receiving evidence of its physical completion. At the outset of this process, the contract administration office must review the contract funds status and notify the contracting office …
  • FAR 4.1301 Policy.
    …determined by the agency: (i) When no longer needed for contract performance. (ii) Upon completion of a contractor employee's employment. (iii) Upon contract completion or termination. (2) The contracting officer may delay final payment…
  • FAR 8.705-4 Compliance with orders.
    …rofit agency or AbilityOne participating nonprofit agency for revision in the delivery or completion schedule, if feasible. If extension of the delivery or completion date is not feasible, the ordering office shall notify the appropriate ce…
  • FAR 11.404 Contract clauses.
    … contracting officer shall insert the clause at 52.211-10, Commencement, Prosecution, and Completion of Work, in solicitations and contracts when a fixed-price construction contract is contemplated. The clause may be changed to accommodate …
  • FAR 11.702 Construction contracts.
    … time if the quantity variation is such as to cause an increase in the time necessary for completion. The contracting officer must receive the request in writing within 10 days from the beginning of the period of delay. However, the contrac…
  • FAR 16.403-2 Fixed-price incentive (successive targets) contracts.
    …rm target cost and firm target profit will be negotiated (usually before delivery or shop completion of the first item). (v) A ceiling price that is the maximum that may be paid to the contractor, except for any adjustment under other cont…
  • FAR 17.204 Contracts.
    …lead time to ensure continuous production. (d) The period may extend beyond the contract completion date for service contracts. This is necessary for situations when exercise of the option would result in the obligation of funds that are n…

FAR (chapter 1)

DFARS (chapter 2, Defense)

Source: eCFR, 48 CFR chapters 1 and 2 (GPO GovInfo bulk data) ↗. Rule changes in progress: FAR, DFARS. Terms: glossary.